The government requires performance of general construction services for NAVFAC Midatlantics Marine Corps Installations MCI East AOR, including North Carolina and South Carolina. The contractor shall begin performance within 15 calendar days and complete it within 365 calendar days after receiving award, notice to proceed. Sealed offers in original and 1 copies to perform the work required are due at the place specified in item 8 by 2:00 pm hour local time 9/23/2025. The government intends to award approximately five 5 contracts resulting from this solicitation to the responsible offerors whose proposals represent the best values after evaluation in accordance with the factors and their relative importance. The completion date for the idiq contracts is one 1 year from the date of contract award with four 4 oneyear option periods, not to exceed 60 months. The total fiveyear base and four 12month options estimated construction cost for all contracts is not to exceed 975,000,000 for the life of the contract. Projects for the macc have an estimated construction cost between 25,000,000 and 150,000,000 however, smaller and larger dollar value projects may be considered at the discretion of the contracting officer. The government guarantees an award amount of 5,000 to each successful offeror. The government will evaluate price and nonprice factors: factor 1 corporate experience, factor 2 management approach, factor 3 safety, factor 4 past performance, factor 5 small business utilization and participation. The government reserves the right to eliminate from consideration for award any or all offers at any time prior to award of the contracts to negotiate with offerors in the competitive range and to award the contracts to the offerors submitting the proposals determined to represent the best value the proposals most advantageous to the government, price and other factors considered.
The contractor shall begin performance within 15 calendar days and complete it within 365 calendar days after receiving award, notice to proceed. The contractor shall begin performance within 15 calendar days and complete it within 365 calendar days after receiving award, notice to proceed.
The government shall make progress payments monthly as the work proceeds, or at more frequent intervals as determined by the contracting officer, on estimates of work accomplished which meets the standards of quality established under the contract, as approved by the contracting officer. The government shall make progress payments monthly as the work proceeds, or at more frequent intervals as determined by the contracting officer, on estimates of work accomplished which meets the standards of quality established under the contract, as approved by the contracting officer.
Award will be made to the responsible offerors whose offer conforms to the solicitation and represents the best value to the government, price and nonprice factors considered. Award will be made to the responsible offerors whose offer conforms to the solicitation and represents the best value to the government, price and nonprice factors considered.
The government intends to award approximately five 5 contracts resulting from this solicitation to the responsible offerors whose proposals represent the best values after evaluation in accordance with the factors and their relative importance. The government intends to award approximately five 5 contracts resulting from this solicitation to the responsible offerors whose proposals represent the best values after evaluation in accordance with the factors and their relative importance, unless more or less than five 5 is determined to be the best value to the government.
If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of see note for each calendar day of delay until the work is completed or accepted. if the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of see note for each calendar day of delay until the work is completed or accepted.
Site visit details for the seed project will be determined via amendment. site visit details for the seed project will be determined via amendment.
The total fiveyear base and four 12month options estimated construction cost for all contracts is not to exceed 975,000,000 for the life of the contract. The total fiveyear base and four 12month options estimated construction cost for all contracts is not to exceed 975,000,000 for the life of the contract.
