Rug Repair Government Bids & RFPs

The resultant contractual delivery requirement is measured from asset return to the date of asset acceptance under the terms of the contract. The resultant contractual delivery requirement is measured from asset return to the date of asset acceptance under the terms of the contract.

The resultant award of this solicitation will be issued bilaterally, requiring the contractors written acceptance prior to execution. The resultant award of this solicitation will be issued bilaterally, requiring the contractors written acceptance prior to execution.

Any asset for which the contractor does not meet the required RTAT will incur a price reduction per unit per month the contractor is late. Any asset for which the contractor does not meet the required rtat will incur a price reduction per unit per month the contractor is late any delay determined to be excusable e. g. government delay will not result in a price reduction. if a price reduction is required due to unexcusable contractor delay, the contracting officer will implement the aforementioned price reduction via a reconciliation modification at the end of the contract performance. price reductions made pursuant to this section shall not limit other remedies available to the government for failure to meet required rtats, including but not limited to the governments right to terminate for default.

The delivery is 45 days after the award date.

The government will award the contract to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the government, price and other factors considered.